×
These Terms & Conditions ("Terms") govern your access to and use of the website, services, software solutions, digital products, consultations, communications, and business engagements provided by Ezulix Software Private Limited ("Ezulix," "Company," "we," "our," or "us").
By accessing our website, requesting information, engaging our services, signing a proposal, executing a Statement of Work (SOW), purchasing services, or otherwise interacting with Ezulix, you agree to be bound by these Terms.
If you do not agree to these Terms, you should discontinue use of our website and services.
Ezulix Software Private Limited is a software development and digital transformation company headquartered in India and serving clients globally.
By using our website or engaging our services, you represent that:
You agree to use our website only for lawful purposes.
You shall not:
We reserve the right to suspend or restrict access where misuse is detected.
Service engagements may be governed by:
Where separate contractual documents exist, those documents shall prevail in the event of any conflict with these Terms.
Clients agree to:
Delays caused by the client may impact delivery schedules and project timelines.
Any timeline, milestone, estimate, roadmap, or projected completion date is provided in good faith based on information available at the time.
Delivery schedules may be affected by:
Ezulix shall not be liable for delays arising from circumstances beyond its reasonable control.
Any modification to approved project requirements may constitute a Change Request.
Change Requests may impact:
Clients agree to pay all fees specified in applicable agreements, quotations, proposals, or invoices.
Unless otherwise agreed:
All taxes, duties, levies, withholding taxes, and governmental charges are the responsibility of the client unless otherwise stated.
Ezulix retains ownership of:
Nothing in these Terms transfers ownership of Ezulix's proprietary technology.
Clients retain ownership of:
Clients grant Ezulix a limited license to use such materials solely for service delivery purposes.
Ownership of final project deliverables shall transfer only upon:
Ownership rights may be further defined in the applicable Service Agreement or Statement of Work.
Projects may involve third-party technologies, including:
Ezulix is not responsible for:
Use of such services remains subject to their respective terms and policies.
Both parties agree to maintain confidentiality regarding non-public business, technical, financial, and operational information exchanged during the course of engagement.
Confidential information shall not be disclosed except:
Confidentiality obligations survive termination of the business relationship.
Use of personal information is governed by our Privacy Policy.
By using our website or services, you acknowledge that personal information may be collected, processed, transferred, and stored in accordance with our Privacy Policy and applicable data protection laws.
Clients shall not use software, applications, websites, AI systems, automation tools, or other deliverables developed by Ezulix for:
Ezulix reserves the right to terminate services where unlawful use is identified.
Except as expressly stated in a written agreement:
To the fullest extent permitted by law, all implied warranties are disclaimed.
To the maximum extent permitted by law, Ezulix shall not be liable for:
In no event shall Ezulix's aggregate liability exceed the total fees actually paid by the client for the specific services giving rise to the claim during the preceding twelve (12) months.
You agree to indemnify and hold harmless Ezulix, its directors, officers, employees, contractors, affiliates, and representatives from claims, damages, liabilities, losses, costs, and expenses arising from:
Ezulix shall not be liable for failure or delay caused by circumstances beyond reasonable control, including:
Ezulix may suspend or terminate services if:
Termination shall not affect accrued payment obligations or rights existing prior to termination.
Ezulix serves clients globally and strives to comply with applicable international legal frameworks, including:
Clients remain responsible for ensuring their own regulatory compliance obligations associated with the use of delivered solutions.
These Terms shall be governed by and construed in accordance with the laws of India.
Any dispute arising out of or relating to these Terms shall be subject to the exclusive jurisdiction of the courts located in Jaipur, Rajasthan, India, unless otherwise agreed in writing between the parties.
Ezulix reserves the right to update, modify, or replace these Terms at any time.
Updated versions will be posted on our website with a revised "Last Updated" date.
Continued use of the website or services following publication of revised Terms constitutes acceptance of the updated Terms.
For questions regarding these Terms & Conditions, please contact:
+1 (714) 670 5883 Ext. 113
+971 55 1017663
+91 92667 30534